1-888-LETS-PAINT

CLIENT:

PASCON

2514 LAMBERT LANE

SAN JOSE, CA

408-461-0433

INTERIOR PAINTING CONTRACT

SCOPE OF WORK:

LATEX AND/OR ENAMEL FOR THE FOLLOWING:

7

ROOM/ITEM DESCRIPTION - ALL ROOMS SPLIT/2 COATS / WALLS & CEILING / QTY/SQ. FT / PRICE EACH / TOTAL /
LIVING ROOM / X / 1 / $351.00 / $351.00
ENTRY / X / 1 / $241.00 / $241.00
DINING ROOM / X / 1 / $342.00 / $342.00
HALL / X / 1 / $407.00 / $407.00
ENTRY CLOSET / X / 1 / $65.00 / $65.00
POWDER ROOM / X / 1 / $222.00 / $222.00
BEDROOM I / X / 1 / $259.00 / $259.00
CLOSET / X / 1 / $185.00 / $185.00
BEDROOM II / X / 1 / $278.00 / $278.00
CLOSET / X / 1 / $56.00 / $56.00
WALK-IN / X / 1 / $241.00 / $241.00
MASTER BEDROOM / X / 1 / $315.00 / $315.00
CLOSET / X / 1 / $129.00 / $129.00
MASTER BATH / X / 1 / $278.00 / $278.00
WATER CLOSET / X / 1 / $185.00 / $185.00
BEDROOM III / X / 1 / $268.00 / $268.00
CLOSET / X / 1 / $74.00 / $74.00
BATHROOM / X / 1 / $278.00 / $278.00
LAUNDRY / X / 1 / $268.00 / $268.00
KITCHEN / X / 1 / $333.00 / $333.00
FAMILY ROOM / X / 1 / $370.00 / $370.00
GARAGE / X / 1 / $370.00 / $370.00
LIVING ROOM CABINETS / 1 / $185.00 / $185.00
DOORS / 22 / $95.00 / $2,090.00
10 PANE FRENCH / 2 / $210.00 / $420.00
CABINETS - FRONT & BACK / 160 / $45.00 / $7,200.00
DOOR & WINDOW TRIM / 714 / $3.00 / $2,142.00
FLOOR & CROWN MOULDING / 1550 / $3.00 / $4,650.00
TOTAL / $22,202.00

DOUGHERTY PAINTING WILL MOVE FURNITURE OVER 60 LBS. DOUGHERTY PAINTING WILL SPEND A TOTAL OF 15 MINUTES PER ROOM, MOVING FURNITURE IN AND OUT. THIS APPLIES TO LIVING ROOM, DINING ROOM, FAMILY ROOM, AND BEDROOMS. SHOULD MOVING FURNITURE IN AND OUT OF A SINGLE ROOM EXCEED A TOTAL TIME OF 15 MINUTES, DOUGHERTY PAINTING WILL CHARGE $65.00/PER MAN HOUR. ALL OTHER ITEMS (CURTAINS, BLINDS, PLANTS, LAMPS, WALL HANGINGS, BOOKS, RUGS, NICK NACKS, ETC...) WILL BE THE RESPONSIBILITY OF CLIENT. SHOULD YOU REQUIRE ADDITIONAL ASSISTANCE, DOUGHERTY PAINTING WILL CHARGE $65.00/PER MAN HOUR. DOUGHERTY PAINTING SHALL NOT BE HELD RESPONSIBLE FOR DAMAGE TO FURNISHINGS OR DAMAGE TO FLOORS CAUSED BY MOVED FURNITURE OR APPLIANCES.

PLEASE NOTE: THIS IS AN EXACT ACCOUNTING OF WHAT THIS CONTRACT IS BID AND BASED ON.

PREPARATION TO INCLUDE:

PATCHING OF HOLES OR CRACKS WHERE NECESSARY. DOUGHERTY PAINTING WILL MOVE ALL FURNITURE OVER 60 LBS. AND ATTACHED FIXTURES WHERE NECESSARY. DOUGHERTY PAINTING WILL MASK, LIGHTLY SAND AND PRIME DOORS, DOOR JAMBS, AND CABINETRY WHEREVER NECESSARY AND SUCH ITEMS ARE PAINTED. COMPLETELY COVER ALL FURNISHINGS, CARPET, FLOORS, WINDOWS, ETC. DOUGHERTY PAINTING WILL NOT BE RESPONSIBLE FOR WALL HANGINGS OR NICK-NACKS WHETHER IN OR ON FURNITURE.

PRODUCT SEPARATION:

IF APPLICABLE, KITCHEN, BATHROOMS, CABINETS, DOORS, AND DOOR JAMBS (THAT WILL RECEIVE PAINT) WILL RECEIVE KELLY-MOORE 1685 SEMI-GLOSS LATEX ENAMEL. ALL FLAT SURFACES TO RECEIVE KELLY-MOORE 550 PREMIUM INTERIOR LATEX. UNPAINTED SURFACES TO BE PAINTED WITH THE APPROPRIATE PRIMERS.

PRODUCT HANDLING:

APPLICATION OF THESE PRODUCTS WILL BE MADE BY BRUSH, ROLLER AND SPRAY.

TERMS AND CONDITIONS

  1. CONTRACTOR TO PERFORM ALL WORK IN A GOOD AND WORKMANLIKE MANNER. CONTRACTOR WILL AT ALL TIMES MAINTAIN PROPER WORKMAN’S COMPENSATION INSURANCE AND WILL COMPLY WITH CALIFORNIA CONTRACTOR’S LICENSE REGULATIONS.
  2. CHECK IS TO BE GIVEN TO JOB FOREMAN AT SATISFACTORY COMPLETION OF JOB. SATISFACTION SPECIFICALLY MEANS MEETING TRADE STANDARDS.
  3. OWNER IS RESPONSIBLE FOR PROVIDING ACCESS, WATER, ELECTRICITY, AND A CLEAN UP AREA. IT IS THE RESPONSIBILITY OF THE OWNER TO OBTAIN PERMISSION, IF IT IS NECESSARY TO GO ONTO OR OVER THE PROPERTY OF ANOTHER TO PERFORM THE CONTRACT.
  4. OWNER IS RESPONSIBLE FOR BEING HOME TO UNLOCK WINDOWS AND DOORS AS REQUIRED AND STAYING HOME UNTIL THOSE WINDOWS AND DOORS HAVE DRIED AND CAN BE SECURED.
  5. OWNER IS RESPONSIBLE FOR KEEPING PETS, CHILDREN, ETC. OUT OF PAINT AND PAINTING AREA.
  6. DOUGHERTY PAINTING SHALL NOT GUARANTEE ANY BRAND OF PAINT OTHER THAN KELLY MOORE, AND SHALL NOT BE HELD RESPONSIBLE FOR ANY DEFECT OR PRODUCT FAILURE FROM ANY PAINT PRODUCTS OTHER THAN KELLY MOORE.
  7. DOUGHERTY PAINTING SHALL NOT BE HELD RESPONSIBLE FOR DAMAGE TO ANY SURFACES CAUSED BY MOVING HEAVY APPLIANCES.
  8. SHOULD CLIENT CHOOSE TO CANCEL THIS CONTRACT FIVE BUSINESS DAYS, OR MORE, AFTER SIGNING, THERE WILL BE A CANCELLATION FEE OF 10% OF THE CONTRACT AMOUNT.

EITHER PARTY, (OWNER OR CONTRACTOR) SHALL BE EXCUSED FOR ANY DELAYS OR DEFAULTS BY THEM IN THE EXECUTION OF THE CONTRACTOR UNAVOIDABLY CAUSED BY THE ACT OF THE OTHER PARTY, THE ACT OF ANY AGENT OF THE OTHER PARTY, THE ACT OF GOVERNMENTAL AUTHORITY, ACTS OF GOD, THE ELEMENTS, OR OTHER CAUSES BEYOND EITHER PARTY’S CONTROL. EACH PARTY SHALL USE REASONABLE DILIGENCE TO AVOID ANY SUCH DELAY OR DEFAULT AND TO RESUME PERFORMANCE UNDER THIS CONTRACT AS PROMPTLY AS POSSIBLE AFTER SUCH DELAY OR DEFAULT.

EXCLUSIONS

UNLESS SPECIFICALLY INCLUDED IN THE CONTRACT, THE FOLLOWING ITEMS ARE EXCLUDED: ALL DOORS, DOOR JAMBS, FLOOR MOLDINGS, CROWN MOLDINGS, ANY VARNISHED SURFACE, ANY UNPAINTED SURFACE, WINDOWS, WINDOW FRAMES, WINDOW SILLS, CABINETRY, VANITIES, CLOSETS, AND LINEN CLOSETS, EXCESSIVE MOVING OF FURNITURE (PICTURES, NICK NACKS, ETC.), PAINTING OF ACOUSTIC OR TILE CEILINGS. DOUGHERTY PAINTING IS NOT RESPONSIBLE FOR MASKING TAPE PROCEDURE DAMAGE. BUILDING IS ESTIMATED TO BE PAINTED THE SAME AS ORIGINAL PAINT STYLE ON BUILDING.

PAINT AND WORK SPECIFICATIONS:

THESE SPECIFICATIONS ARE INTENDED TO EMBRACE ALL OF THE LABOR AND MATERIALS NECESSARY IN THE COMMENCEMENT AND COMPLETION OF THE PAINTING IN ALL ITS PARTS. THE WHOLE TO BE COMPRISED WITHIN ANY CONTRACT OR CONTRACTS THAT MAY BE MADE FOR THE SAME.

THE ENTIRE WORK IS TO BE STARTED AND FINISHED IN EVERY PART IN A GOOD, SUBSTANTIAL AND WORKMAN-LIKE MANNER ACCORDING TO THESE SPECIFICATIONS TO THE FULL EXTENT AND MEANING OF THE SAME, AND TO THE REASONABLE APPROVAL AND ACCEPTANCE OF THE OWNER OR THE OWNER’S AGENT.

THE CONTRACTOR SHALL PROVIDE ALL MATERIALS AND LABOR NECESSARY FOR THE COMPLETE AND SUBSTANTIAL EXECUTION OF EVERYTHING DESCRIBED, SHOWN, OR REASONABLY IMPLIED. THIS INCLUDES ALL TRANSPORTATION, MATERIALS (UNLESS OTHERWISE PARTICULARLY SPECIFIED TO BE THE BEST OF THEIR RESPECTIVE KIND) AND ALL WORKMANSHIP TO BE THAT OF SKILLED PROFESSIONAL PAINTERS.

THE CONTRACTOR IS TO MAINTAIN AT ALL TIMES A COMPETENT FOREMAN ON THE JOB. HE IS TO EXECUTE THE WORK WITH DUE DILIGENCE AND EXPEDITION. HE IS TO GIVE IMMEDIATE ATTENTION TO THE DIRECTIONS OF THE OWNER’S REPRESENTATIVE AND WILL BE HELD RESPONSIBLE FOR VARIATIONS FROM SPECIFICATIONS. HE SHALL MAINTAIN AND GUARANTEE THE STABILITY OF THE WORK; AND REPAIR ANY DEFECTIVE WORK FOR A PERIOD OF FIVE YEARS AFTER COMPLETION OF THE CONTRACT.

DOUGHERTY PAINTING’S 5 YEAR GUARANTEE

DOUGHERTY PAINTING, INC. GUARANTEES THAT ANY MATERIALS APPLIED BY US WILL WEATHER NORMALLY FOR THE LIFE OF THE PAINTING, FOR A PERIOD OF FIVE YEARS. THIS PERTAINS ONLY TO THE IMMEDIATE SURFACE TO WHICH OUR MATERIALS ARE APPLIED AND DOES NOT APPLY UNDER EXTRAORDINARY CIRCUMSTANCES SUCH AS EXCESSIVE WEATHER EXPOSURE, CUSTOM COLORS, DEEP-TONE COLORS ON LARGE SURFACES, PAINTS NOT SUPPLIED BY US, OR ANY OTHER FAILURE BEYOND OUR CONTROL. THIS GUARANTEE SPECIFICALLY EXCLUDES FAILURE DUE TO IMPROPER PREVIOUS MAINTENANCE SUCH AS PRIOR PAINTING OVER UNPREPARED SURFACES, AND HORIZONTAL SURFACES SUCH AS DECKS, PORCHES AND WALKWAYS. IF ANY PAINT FAILURE SHOULD OCCUR WITHIN A 5 YEAR PERIOD, DOUGHERTY PAINTING WILL REPAIR PROBLEM, DEEMED FAIR AND ACCEPTABLE BY US IN ACCORDANCE WITH THE CALIFORNIA STATE CONTRACTING LAWS AND PROCEDURES RECOMMENDED BY THE BETTER BUSINESS BUREAU.

COATS:

THIS JOB HAS BEEN BID AT ONE COAT. IF HOWEVER THE CLIENT CHOOSES A COLOR THAT WILL REQUIRE EXTRA COATS, THERE WILL BE AN EXTRA CHARGE. TWO COATS TO BE APPLIED OVER UNPAINTED OR PATCHED SURFACES.

PAINT:

ALL PAINTS AND OTHER MATERIALS USED WILL BE KELLY-MOORE PREMIUM QUALITY OR CUSTOMER’S CHOICE.

COLORS:

PRICE QUOTED IS FOR COLORS TO BE PICKED FROM THE COLOR CHART SUPPLIED. COLOR AND COLOR PLACEMENT TO BE PICKED BEFORE THE JOB BEGINS. COLORS WILL NOT MATCH CHIPS EXACTLY.

$85 EXTRA CHARGE PER COLOR CHANGE IF MORE THAN 2 COLORS ARE USED

ALTERATIONS:

IT IS ALSO UNDERSTOOD THAT THE OWNER’S REPRESENTATIVE SHALL HAVE THE RIGHT TO MAKE ANY ALTERATIONS, ADDITIONS, OR OMISSIONS OR WORK OR MATERIALS HEREIN SPECIFIED DURING THE PROCESS OF THE BUILDING THAT THEY MAY FIND NECESSARY. THE SAME SHALL BE ACCEDED TO BY THE CONTRACTOR AND CARRIED INTO EFFECT WITHOUT VIOLATING THE INTEGRITY, OR THE QUALITY OF WORK LAID OUT IN THE CONTRACT. THE VALUE OF ALL SUCH ALTERATIONS, ADDITIONS OR OMISSIONS SHALL BE AGREED UPON IN WRITING BETWEEN THE CONTRACTOR AND OWNER’S REPRESENTATIVE BEFORE GOING INTO EXECUTION. NO EXTRA WORK WILL BE ALLOWED WITHOUT SUCH WRITTEN AGREEMENT, FURTHERMORE; IF ANY PARTY HERETO COMMENCES AN ACTION OR ARBITRATION PRECEDING TO INTERPRET OR ENFORCE THIS CONTRACT OR ANY PROVISIONS HEREOF, THE PREVAILING PARTY SHALL BE ENTITLED TO AN AWARD OF COSTS AND ATTORNEYS’ FEES IN ADDITION TO ALL OTHER AMOUNTS AWARDED BY THE COURT OR ARBITRATOR.

PREPARATION AND PAINTING NOTES

DOUGHERTY PAINTING, INC. RESERVES THE RIGHT TO RE-ESTIMATE ANY JOB FOR ANY OF THE FOLLOWING REASONS: SANDBLASTING DONE AFTER A PREVIOUS ESTIMATE. CONTINUED OR ADVANCED WEATHERING. THIRTY DAYS EXPIRED. ANY CHANGE REQUESTED. OTHER CHANGES THAT WOULD AFFECT PRICE.

COMPLETION TIME:

APPROXIMATELY 21 WORKING DAYS FROM START DATE.

EXPERIENCE:

OVER THIRTY-FIVE YEARS OF PAINTING EXPERIENCE SPECIALIZING IN RESIDENTIAL AND CUSTOM HOME PAINTING. WE TAKE PRIDE IN DOING SUPERIOR WORK, OFFERING PERSONALIZED SERVICE AND BEING DETAIL ORIENTED.

PAYMENT SCHEDULE:

TOTAL COST OF JOB

$22202.00

PAYMENT IS DUE IN FULL ON DAY OF COMPLETION

CHANGE ORDERS/ADDITIONS CREATED BY THE CLIENT WILL BE AT THE RATE OF $65.00 PER MAN HOUR.

MICHAEL DOUGHERTY

OWNER, DOUGHERTY PAINTING, INC.

______/____/____

OWNER OR OWNER REPRESENTATIVE

______/____/____

CLIENT HAS THE RIGHT TO CANCEL THIS CONTRACT IN WRITING WITHIN 3 DAYS OF SIGNING. ALL CONTRACTORS RECORDS ARE ON FILE IN SACRAMENTO. YOU MAY INQUIRE ABOUT ANY CONTRACTOR BY CALLING THE STATE BOARD OF CONTRACTORS PH #800-321-2752.

DOUGHERTY PAINTING WILL SUPPLY THE CLIENT WITH PROOF OF WORKMEN’S COMPENSATION INSURANCE, PUBLIC LIABILITY AND PROPERTY DAMAGE INSURANCE ($500,000.00 IN COVERAGE).

7